Jones v St John's College Oxford
This information is only available to paying isurv subscribers.
(1870) LR 6 QB 115
Construction contracts - liquidated damages - delay - agreement to complete works by certain date subject to alterations or additions - whether extra works to be carried out by same date
The claimant was a building contractor who agreed to...